Documents

(Opinion issued on June 18, 2013, without redactions or protective legends)

Agency decision · Agency decision

Examples of such cases include (1) acts of God or of the public enemy, (2) acts of the United States Government in either its sovereign or contractual capacity, (3) acts of the government of the host country … Further, notes by another individual attribute to the Regional Security Officer comments that September and October had been a period of increased unrest, that UN peacekeepers and new police were trying

DISMISSED IN PART FOR LACK OF JURISDICTION: September 4, 2013

Agency decision · Agency decision

Respondent argues that the Contract Disputes Act (CDA), 41 U.S.C. § 7103(a) (Supp. … General Services Administration, GSBCA 16093, 03-2 BCA ¶ 32,345, at 160,041 (quoting Contract Cleaning Maintenance, Inc. v. United States, 811 F.2d 586, 592 (Fed. Cir. 1987)).

In the Matter of SAMANTHA J. INGRAM

Agency decision · Agency decision

[the Department of Defense] does not contend that the amount exceeds the fee customarily paid.”1 Discussion This claim is governed by the Federal Travel Regulation (FTR), and since the claimant is an Air … However, if the wire fee was incurred by the lender, it is an unallowable finance charge under the Truth in Lending Act and Regulation Z and not reimbursable. 4 A title insurance binder is a “separate

NATIONAL ARCHIVES AND RECORDS ADMINISTRATION,

Agency decision · Agency decision

In the event the prevailing wage rate or collective bargaining wage rates are subject to an increase during a period of contract performance, FAR clause 52.222-43, “Fair Labor Standards Act and Service … In CAE, the Air Force awarded a successor contract for the provision of support services for its Aircrew Training System (ATS).

MOTIONS TO DISMISS FOR LACK OF JURISDICTION

Agency decision · Agency decision

The term of the lease is established in a rider, paragraph 13, to be a firm period of ten consecutive calendar years, subject to specified termination rights. … Army & Air Force Exchange Service, 846 F.2d 746, 747 (Fed. Cir. 1988); Kentucky Bridge & Dam, Inc. v. United States, 42 Fed. Cl. 501, 515 (1998); CACI, INC.- FEDERAL v.

GRANTED: February 7, 2022

Agency decision · Agency decision

Performance may consist of an act or a forbearance. Id. § 71(3). … The clause specifically identified items such as asbestos, heat, ventilation, air conditioning, maintenance records, leaks, spills, and hazardous material as potentially warranting inspection.

GRANTED IN PART : February 11, 2016

Agency decision · Agency decision

A contractor or subcontractor bidding work to PJB or its prime, such as a price for heating, ventilating, and air conditioning (HVAC) or ceilings, would not break out or allocate pricing between what was … Having found entitlement as noted above, we briefly comment on defenses raised by GSA asserting defects in appellant’s proof as to delays.

MOTION FOR SUMMARY RELIEF DENIED: December 22, 2016

Agency decision · Agency decision

General Heating & Air Conditioning, Inc. v. General Services Administration, CBCA 1242, 09-2 BCA ¶ 34,256, at 169,264 (quoting AFR & Associates, Inc. v. … If a contract with the Government contains a term limiting a contractor’s right to bring claims to a period less than the six-year period for which the CDA provides, or (as in this case) to notify the

In the Matter of ST. MARK’S EPISCOPAL CHURCH

Agency decision · Agency decision

Stafford Disaster Relief and Emergency Assistance Act (Stafford Act), 42 U.S.C. §§ 5121–5207 (2018), St. Mark’s Episcopal Church (St. … The incident period for Hurricane Irma’s disaster declaration was September 4 through October 18, 2017. St.

In the Matter of HOUSING AUTHORITY OF THE CITY OF

Agency decision · Agency decision

Stafford Disaster Relief and Emergency Assistance Act, as amended, 42 U.S.C. § 5189a (2018). … The PW stated further that there would be an attempt to salvage the heating, ventilation and air conditioning (HVAC) system, hot water heaters, cast iron tubs, sinks, and toilets. Exhibit 7.

DENIED: July 24, 2017

Agency decision · Agency decision

On May 30, 2014, AWI had a potential mechanical subcontractor, Mid AIR Mechanical (Mid AIR), conduct a walk through of the job site to review the status of the mechanical and plumbing work terminated from … Sironi, AWI did not inform the VA of any plan to bring Mid AIR into the project as B&K’s replacement mechanical subcontractor.

In the Matter of DAVID C. TURNBULL

Agency decision · Agency decision

Government employees who use commercial air carriers for domestic and international travel on official business must use coach-class airline accommodations.” 14 FAM 567.2. … Here, claimant acted prudently and consistent with the FAM in purchasing the upgraded seats. Decision The claim is granted.

MOTION TO DISMISS GRANTED IN PART AND

Agency decision · Agency decision

Army & Air Force Exchange Service, 846 F.2d 746, 748 (Fed. Cir. 1988). II. … “While a board cannot extend the time for appeal, an appeal period can be tolled where one finds that a [contracting officer’s] decision was not truly final but was being reconsidered.

DENIED: April 7, 2023

Agency decision · Agency decision

Examples of such delays include, but are CBCA 6453, 6560 9 not limited to, acts of God, acts of the Government in either its sovereign or contractual capacity, floods, fires, epidemics, and unusually … “When the contract does not specify a period in which the government must respond, the law imposes an obligation to act within a reasonable period of time.” Essex Electro Engineers, Inc. v.

DENIED: September 10, 2019

Agency decision · Agency decision

In June 2014, the VA awarded a second firm-fixed-price contract to Stobil to extend the housekeeping services contract for a six-month period, from July 1 to December 31, 2014. … Air Masters Corp. v. General Services Administration, GSBCA 16327, 04-2 BCA ¶ 32,688, at 161,746.

GRANTED IN PART: February 18, 2015

Agency decision · Agency decision

After the Board denied GSA’s request for reconsideration, SIM submitted an application for reimbursement of fees and costs under the Equal Access to Justice Act (EAJA or the Act), 5 U.S.C. § 504 (2012) … CBCA 3815-C(1512), 3816-C(1537) 5 Finally, SIM seeks costs for such expenses as air delivery service, color copies, couriers, depositions and transcripts, duplicating, travel, lodging, and meals.

MOTION TO DISMISS FOR LACK OF JURISDICTION DENIED;

Agency decision · Agency decision

Referencing a “breach of contract”, CEC sought $12,667 for additional costs relating to increased slab capacity; $5041 for extra work associated with the heating, ventilation, and air-conditioning (HVAC … In its reply, CEC clarifies the nature of its claim to be comparable with claims for lost profits: Being a small engineering business, during the period preceding the arbitration outcome, because of the

GRANTED IN PART: April 6, 2016

Agency decision · Agency decision

and for each of four option periods. … Delta Air Lines, Inc. v. General Services Administration, CBCA 1306, 09-1 BCA ¶ 34,052, at 168,408 (quoting 31 U.S.C. § 3907(c)).

APPELLANT’S MOTION FOR PARTIAL SUMMARY JUDGMENT

Agency decision · Agency decision

The contract had an initial one-year contract period and four one-year option periods. … Initial Contract Award: If the basis of award involves evaluating options and/or award terms, the dollar value of the individual transaction must include the base period and all option periods, the award

CBCA 8202 DENIED; CBCA 8203 RESPONDENT’S MOTION

Agency decision · Agency decision

Again, as stated prior, we cannot do a final until the snow is completely gone from each post and we can do an inspection and determine if the site has been cleaned up properly. … Has Not Established Entitlement to Prompt Payment Act Interest F.O.G. claims that it is entitled to interest under the Prompt Payment Act (PPA), 31 U.S.C. § 3901–3907 (2018), caused by BLM’s alleged delay