THIS OPINION WAS INITIALLY ISSUED UNDER PROTECTIVE ORDER AND

THIS OPINION WAS INITIALLY ISSUED UNDER PROTECTIVE ORDER AND

IS BEING RELEASED TO THE PUBLIC IN ITS ENTIRETY ON

APRIL 20, 2017

GRANTED IN PART: April 10, 2017

CBCA 5517

DREAM MANAGEMENT, INC.,

Appellant,

v.

DEPARTMENT OF HOMELAND SECURITY,

Respondent.

Timothy Sullivan and Jayna Marie Rust of Thompson Coburn LLP, Washington, DC,

counsel for Appellant.

Kasey Podzius, Office of the Principal Legal Advisor, Immigration and Customs

Enforcement, Department of Homeland Security, Washington, DC, counsel for Respondent.

BEARDSLEY, Board Judge.

Appellant, Dream Management, Inc. (DMI), appealed the denial of its claim for costs

incurred in performing a language services contract for the Department of Homeland

Security, Immigration and Customs Enforcement (ICE). Appellant asserts that the agency

breached the contract, or in the alternative, the agency terminated the contract for its

convenience. Appellant has elected to proceed under the Board’s expedited procedure for

small claims. Rule 52 (48 CFR 6101.52 (2015)). Decisions issued under the small claims

CBCA 5517

2

procedure are final and conclusive and shall not be set aside except in cases of fraud

affecting the Board’s proceedings. Rule 52(b); see 41 U.S.C. § 7106(b) (2012); Palmer v.

Barram, 184 F.3d 1373 (Fed. Cir. 1999). This decision has no value as precedent.

Background

Federal Supply Schedule Contract

DMI holds a Federal Supply Schedule (FSS) contract (FSS contract) with the General

Services Administration (GSA), contract number GS-10F-222BA, to provide Spanishlanguage translation and interpretation services. The GSA FSS contract terms and conditions

(GSA terms and conditions) contained Federal Acquisition Regulation (FAR) clause

52.212-4(l) (48 CFR 52.212-4(l) (2015)), “Contract Terms and Conditions - Commercial

Items (May 2014) (Alternate I - May 2014) (Deviation I - Feb 2007).” Stipulated Facts ¶ 3.

That clause, titled “Termination for the Ordering Activity’s Convenience,” stated:

The ordering activity reserves the right to terminate this contract, or any part

hereof, for its sole convenience. In the event of such termination, the

Contractor shall immediately stop all work hereunder and shall immediately

cause any and all of its suppliers and subcontractors to cease work. Subject to

the terms of this contract, the Contractor shall be paid an amount for direct

labor hours (as defined in the Schedule of the contract) determined by

multiplying the number of direct labor hours expended before the effective

date of termination by the hourly rate(s) in the contract, less any hourly rate

payments already made to the Contractor plus reasonable charges the

Contractor can demonstrate to the satisfaction of the ordering activity using its

standard record keeping system that have resulted from the termination. The

Contractor shall not be required to comply with the cost accounting standards

or contract cost principles for this purpose. This paragraph does not give the

ordering activity any right to audit the Contractor’s records. The Contractor

shall not be paid for any work performed or costs incurred that reasonably

could have been avoided.

Exhibit 1 at 15.1 The only other clause that allowed for any type of cancellation of the

contract was a “Termination for Cause” clause. Id. The FSS contract included a price list

for services provided, including hourly rates for Spanish-language interpretation services.

Id. at 5. The FSS contract included the following terms:

1

All exhibits are found in the appeal file, unless otherwise noted.

CBCA 5517

3

Maximum order: $1,000,000.00

Minimum order: $100.00

Id. at 2.

On April 15, 2015, ICE posted a request on GSA’s eBuy website for “Kiche2 and

other indigenous language translations.” Stipulated Facts ¶ 4. K’iche’ is an indigenous

Guatemalan dialect spoken by less than ten percent of Guatemalans. On May 14, 2015, the

agency issued a request for quotations (RFQ) and statement of work (SOW)3 to eligible

vendors. Stipulated Facts ¶ 13; Exhibit 2 at 2. The RFQ stated that “[t]he basis for award

of any resulting Task Order will be lowest price and technical acceptability, in accordance

with FAR 8.405-3 and 8.404-(d). . . . Multiple awards may be made, if determined to be in

the best interest of the Government.” Exhibit 2 at 3. The RFQ required quoters to provide,

“[f]or estimation and quote submission,” pricing for a twelve-month period of performance

based on the following estimates:

4,583 Base Hours

2,000 Optional Hours

2,000 Additional Optional Hours

Maximum Hours: 8,583

Exhibit 2 at 3 (emphasis omitted). The SOW also provided that “[t]he awardee will have 60

days from the date of the award to hire all required staff for this requirement. The awardee

will need to be operational No Later Than (NLT) 60 days after the award has been made.”

Exhibit 3 at 3. ICE executed a determination and findings (D&F) justifying entering into a

task order on a time and materials basis. Exhibit 27 at 2.

To arrive at the estimated number of base hours for the task order, an ICE contracting

officer’s representative (COR) used the estimated amount of interpretation services used by

ICE under another contract and multiplied that number by the percentage of families

detained. Transcript at 234-36, 283-84, 285-87. The resulting number was an estimated

minutes total. Id. The COR used that estimated minutes total, but mistakenly labeled it

hours, and multiplied that number by the percentage of Guatemalan detainees to arrive at an

2

The documents contained various spellings of the K’iche’ language, but for

the purposes of this decision, we will spell it “K’iche’.”

3

The original SOW was revised by the agency and sent to bidders that same

day. Exhibit 3. This decision will address the revised SOW.

CBCA 5517

4

estimated total. Id. The COR, therefore, arrived at an estimated 4583 base hours, or 274,980

minutes needed. Id. Had the COR been consistent and used minutes throughout his

calculations, the agency estimate would have been 99 base hours, or 5940 minutes. Id.; see

also Appellant’s Post-Hearing Brief at 5. ICE records show that the agency used

approximately 156.98 hours of language interpretation services for the entire twelve-month

period of performance. Transcript at 307-13.

The SOW required the provision of certain minimum services, which were:

An 800 telephonic number and/or tele-video services with preference for 24hour, 7 days per week basis, billed in 15-minute increments rounded to the

nearest quarter hour with 1 hour minimum requirement. At a minimum, the

Government requires translation services that can be conducted within 24

hours of being scheduled.

Exhibit 3 at 2. The SOW also stated that, “[t]he average length of a call for telephonic

interpretation is 30 minutes. [Enforcement Removal Operations (ERO)] estimates calls will

consume 75% of the 4,583 hours for the base year.” Id.

Various vendors submitted questions to the agency, which responded in an email

message to all vendors. One question asked:

So are you saying that I can bid on ONLY the telephonic (OPI) portion of the

SOW? Am I correct that the volume for OPI is approximately 30K minutes

per month? Of this, how much is for K’iche and Mam? That seems like a

very high volume for such obscure languages.

Exhibit 4 at 1. The agency answered by stating:

We estimate that about two-thirds to three-quarters of the time is for oral

translations while the rest will be to create documents and record DVDs with

voiceovers describing activities and regulations at each center. And we will

record those DVDs each time we expand or change a configuration of our

detention facilities or a policy.

Id. Another question asked:

What is the actual number of minutes projected monthly for the telephonic

portion of this project? (Based on the calculation of 75% of 4583 hours,

interpreting volume appears to be approximately 30,000 minutes per month).

CBCA 5517

5

Does this include on-site and if so, can you please provide the telephonic

volume only with a breakdown by language?

Id. (emphasis omitted). The agency’s response was as follows: “The average length of a call

for telephonic interpretation is 30 minutes. ERO estimates calls will consume 75% of the

4,583 hours for the base year. Estimates are for 3,437 hours for the Base Year.” Id. DMI

stated that the high agency estimate was a “critical factor” in the company’s decision to bid

on the task order. Transcript at 54. The company stated that the agency’s actual requirement

of ninety-nine hours would have been too low for DMI to provide services priced within its

GSA schedule rate. Exhibit 4 at 1 (“As stated within the RFQ, all pricing has to be in

accordance with GSA rates.”). DMI understood, however, that the estimated hours were not

a guaranteed minimum, but instead thought that the hours were a target. Transcript at 56,

137, 210; Exhibit 30 at 2.

DMI also understood that the agency may not order the estimated number of base

hours. Transcript at 128. DMI’s president and chief executive officer testified that in his

experience, Government orders came “pretty close to the base numbers that they provide,”

but may not reach those estimated number of hours. Id. at 129. DMI also understood that

“the number of hours probably were for different languages” and thus the required services

for the K’iche’ language may not reach the 4583 hours estimated. Id. at 127.

DMI emailed ICE its quote on June 2, 2015. The quote provided a total price based

on the estimated number of base and option hours. Specifically, the quote provided, “Base

hours, 4583 at $1.38 per minute = $379,472.40.” Exhibit 8 at 8. The quote also stated that

“[w]e expect to cover broad business hours. We are not able to offer 24 hour coverage at this

time.” Id.

Task Order Award

On June 4, 2015, ICE awarded DMI order no. HSCEDM-15-F-00031 (the task order).

Stipulated Facts ¶ 34; Exhibit 8 at 1. The task order stated: “This is an incrementally funded,

Time & Materials, Task Order against the contractor’s GSA schedule contract identified

above. All services shall be provided and invoiced for in accordance with the Contractor’s

GSA terms and conditions and rates proposed in the Contractor’s quote, attached to this Task

Order.” Exhibit 8 at 2. Attached to the task order was the SOW and DMI’s quoted price of

$1.38 per minute for 4583 hours, which equals $379,472.40. Id. The GSA terms and

conditions were specifically referenced. Id. The task order also incorporated by reference

the clause at FAR 52.232-7, “Payments under Time-and-Materials and Labor-Hour contracts

(AUG 2012),” id. at 3, which provides in relevant part:

CBCA 5517

6

The Government will pay the Contractor as follows upon the submission of

vouchers approved by the Contracting Officer or the authorized representative:

(a) Hourly rate. (1) Hourly rate means the rate(s) prescribed in the contract for

payment for labor that meets the labor category qualifications of a labor

category specified in the contract that are—

(i) Performed by the Contractor;

(ii) Performed by the subcontractors; or

(iii) Transferred between divisions, subsidiaries, or affiliates of the Contractor

under a common control.

....

(4) The hourly rates shall include wages, indirect costs, general and

administrative expense, and profit. Fractional parts of an hour shall be payable

on a prorated basis.

48 CFR 52.232-7.

The task order provided for a ceiling price of $379,472.40, which was directly taken

from DMI’s quotation. Exhibit 8 at 8. There was no minimum price listed on the task order.

See id. The task order’s stated period of performance was from June 4, 2015, to June 3,

2016. Id. DMI had sixty days from June 4, 2015, to become operational, which required the

interpretation line to function on August 3, 2015. See Exhibit 3 at 3. ICE made two

additional task order awards with similar hourly estimates to two other contractors.

Stipulated Facts ¶¶ 40, 41; Transcript at 288-89. There is no evidence that DMI knew of the

other two awards.

Prior to award of the task order, a DMI language specialist had identified through

research the subcontractor DMI intended to use for the work. Transcript at 189, 195-96.

Following award of the task order, DMI negotiated with this subcontractor for twenty-four

hours a day, seven days a week interpretation services. On July 14, 2015, prior to finalizing

the subcontract agreement, DMI sent a clarification email to ICE asking:

I have just left a phone message to the effect that we believe we have very

close to 24/7 telephonic coverage ready, yet in order to pay for 24/7, the influx

of calls has to pay for it by approaching the base of 4583 hours. Any technical

or administrative considerations which must be handled prior to

commencement of service we wish to handle quickly. Please comment on how

the agency assesses demand relative to the base hours and we will assemble a

CBCA 5517

7

compendium of all end-user information to be used for interpretation—the

number to call, the billing code to enter, etc.

Exhibit 9 at 1-2. ICE responded that same day by stating: “As far as the contractual aspect

goes, there is no guarantee in the number of hours we may order. The specified hours simply

state the maximum hours we may require under each [contract line item number (CLIN)].”

Id. After a series of email messages between a DMI language specialist and the

subcontractor, only one of which was sent by DMI’s chief executive officer, DMI executed

a subcontractor agreement on July 17, 2015, for K’iche’ interpreters. Stipulated Facts ¶ 49;

Exhibits 29, 30, 31, 32. The agreement required “[a] minimum of 21,500 minutes per

month” and stated that “[i]n the event DHS does not meet the minimum required 21,500

minutes in a month, [the subcontractor] will bill Dream Management for 22,500 minutes.”4

Stipulated Facts ¶ 49; Exhibit 32 at 6. The agreement did provide that the 22,500 minute

minimum would only cover three months and that DMI could “reset the agreement” after

DMI assessed the agency’s actual demands. Transcript at 74. The agreement further stated

that DMI would be charged $1.25 per minute. Exhibit 32 at 6.

Performance of Task Order

On July 24, 2015, DMI informed the agency by email that “staff has been hired and

is being trained for service. If we can beat 3 August and start sooner I’ll tell you

immediately.” Stipulated Facts ¶ 51. The agency COR’s response stated, “Ok, Good news.

I will be on leave from July 31 until August 5.” Id. On August 5, 2015, DMI again

contacted ICE to inform the agency that “although [DMI] projected a 3 August start-up we

encountered slow onboarding, training and vetting of staff.” Exhibit 33 at 2. The email

message further stated that DMI would be ready for service on August 9, 2015, and would

send access information to the language line by the evening of August 7, 2015. Id. The COR

responded, “No problem. Thanks for the update.” Id. at 1.

On August 10, 2015, DMI emailed ICE with the call-in information and explained that

the line was “live.” Exhibit 10 at 2. The ICE COR responded that same day, stating that he

would need to send instructions and sign-in sheets to the field offices, which “may take until

early next week to make its way through the approval process.” Exhibit 10 at 1. However,

unbeknownst to DMI, the call-in information was required to go through “at least four or five

4

It is not clear whether the minimum number of minutes in the subcontract is

21,500 or 22,500. The subcontract states two different numbers and the representations of

the parties provide no clarification. Stipulated Facts ¶ 49; Exhibit 32 at 6; Transcript at 7172. This decision will use 22,500 minutes.

CBCA 5517

8

steps” before being distributed to the ICE field offices and could take around thirteen days.

Transcript at 239-40, 242.

On August 18, 2015, an email message was sent to ICE field offices with call-in

information for the other two awardees, but not for DMI. Stipulated Facts ¶ 54; Transcript

at 238-39. The other two awardees had gone live before August 3, 2015. Transcript at 238.

DMI’s delay in going live caused the approval process to be delayed and behind the other

two awardees. Id. at 237-38. ICE anticipated that a “third vendor will come on-line in

September with capability to provide 24-hour service with immediate response.” Stipulated

Facts ¶ 54. ICE, however, never sent call-in information for DMI to its field offices, and it

never informed DMI of the fact that while it was live and on standby, no ICE user had the

number or could call in. Transcript at 269.

DMI informed ICE on August 21, 2015, that it had not seen any usage on the account.

Exhibit 11 at 2. The email message further stated, “If we need to modify our resource

deployment over time we rely on your input. Please share your observations on how service

usage is projected.” Id. The ICE COR responded on August 24, 2015, informing DMI that

“on Friday, a judge ordered our three family centers closed by October 23. We are currently

awaiting to hear how the agency will proceed. I will keep you in the loop once I know

more.” Exhibit 11 at 1. The email message did not explain that ICE had not yet distributed

DMI’s call-in information to its field offices, which would have accounted for the lack of

usage of the line. Id.

ICE emailed DMI with an update on September 1, 2015. In the email message, the

ICE COR explained that the court ruling limited the amount of time families may remain in

ICE custody but that the agency still had a need for DMI’s services. Exhibit 12 at 1. DMI

responded to ask whether the services should be “paused” until the agency was ready, to

which the ICE COR replied, “I’d say idle them for at least 2 weeks . . . more likely 3-4, but

I won’t know until mid-Sept.” Exhibit 13 at 1. At noon on September 3, 2015, DMI

informed its subcontractor that it should “expect to be idle,” so the subcontractor “put a hold”

on the account for one week, during which time the agency would not be able to reach an

interpreter if it called the line. Exhibit 35 at 3; Transcript at 88, 144-45, 220-21. Neither the

GSA terms and conditions nor the task order contained a suspension clause. See Exhibits

1, 8.

Contract Modification

On September 9, 2015, DMI attempted to clarify with ICE “when lines should be live”

again after the pause. Exhibit 14 at 1. The agency COR responded, “I’ll need to confer later

CBCA 5517

9

this week with my chief who is still out from the long weekend.” Id. A few days later, on

September 14, 2015, DMI emailed the ICE contracting officer stating:

Since we received communication from Mr. Caruso on the court ruling . . . we

have analyzed the situation about the K’iche line and determined that this

situation as it is, is not sustainable for us. The K’iche interpreter line had not

been used at all in the past month we had it live, and we have incurred in [sic]

significant costs to set it up and maintain it based on the contract estimated

amounts.

In order to maintain this line we have to have interpreters standing by around

the clock to satisfy the requirements in the contract. The dialect is very

difficult to source, [e]specially when it is a 24/7 operation. We cannot longer

[sic] keep interpreters just waiting.

We are asking you to entertain the possibility of cancelling the contract if you

think we won’t have the stated activity outlined in the contract, because we

both cannot continue to incur in [sic] costs that are unnecessary. This is an

attempt to mitigate costs.

Exhibit 15. The email message further stated that “[s]o far the costs of setting the line up and

keeping the interpreters on stand by has made us to incur in more than $25,000.” Id. The

ICE contracting officer in turn, emailed the COR for advice, stating that “Dream

Management has reached out to us requesting that we terminate their contract. I assume they

don’t want to default and then we terminate it.” Appellant’s Hearing Exhibit 1. The email

message included a few options that ICE could take in regards to the DMI contract, “let them

off the hook and amicably terminate the remainder of their contract, require them to perform

and see if they decide to just default, restructure the contract and give them a guaranteed

minimum monthly amount regardless of our actual usage. Please let me know what you

think.” Id. The ICE COR’s response stated, “Please terminate the remainder of their

contract per their request.” Id.

On September 16, 2015, DMI received an email message stating, “Per your request,

please review, sign and return the attached modification for the above mentioned Task

Order.” The modification stated that its purpose was “to change the period of performance

to end on 9/16/2015” and that “[a]ll other terms and conditions remain the same.” Exhibit

16 at 2. DMI signed the modification that day; the ICE contracting officer signed it the

following morning. Id.

CBCA 5517

10

Payment Negotiations

On October 26, 2015, DMI emailed an invoice to ICE for $39,630.84. Exhibits 17,

18. The invoice requested payment for 22,500 minutes per month prorated, which DMI

described as the “minimum amount.” Id. ICE rejected the invoice on November 2, 2015,

because according to ICE, the contract “had no guaranteed minimum” and DMI had not

performed any services. Exhibit 19.

DMI subsequently sent a letter on January 13, 2016, to the ICE contracting officer

requesting relief. Exhibit 20. The total amount requested was $60,296.87, which included

$48,645 for the “minimum hours under the Contract” and $11,651.87 for costs in pursuing

resolution of the issue. Exhibit 20 at 10. After receiving no response from the contracting

officer, DMI sent a letter on March 21, 2016, converting the January 13th request to a claim.

Exhibit 21.

On June 8, 2016, ICE stated, “Although I agree . . . that your purchase order contained

no guarantee as to the number of hours we would order[,] I do agree that you would have

incurred start-up costs to prepare for performance under the purchase order.” Exhibit 49.

ICE then asked for an explanation “of the actual costs [DMI] incurred to set up the line, hire

the K’iche interpreters, and have them on stand-by.” Id. DMI responded on July 1, 2016,

outlining its costs incurred.

DMI’s explanation included two invoices from its subcontractor and a table with a

breakdown and explanation of costs. The invoices received from the subcontractor totaled

$35,897.50. Exhibit 22 at 6. These invoices are further supported by four checks DMI sent

to its subcontractor. Exhibits 45, 46, 48, 50. The checks are dated, in order, February 15,

2016, for a sum of $10,000; March 22, 2016, for a sum of $12,948.75; June 6, 2016, for a

sum of $6000; and June 9, 2016, for a sum of $6948.75. Id. The table of costs claimed

included:

costs incurred in setting up the line

$4,816

costs incurred in hiring the interpreters and having them on

standby

$35,897.50

[general & administrative (G&A)] costs

$2,442.81

profit

$2,157.82

the costs incurred in seeking a resolution to the issue

$17,316.91

[Total]

$62,001.04

CBCA 5517

11

Exhibit 22 at 3 (emphasis added). DMI presented a further breakdown of its costs incurred

in setting up the line:

Administrative

Costs

Researching for sources to

staff the line

$1,456

56 hours (language

specialist) X

$26/hour

Interviewing interpreter

candidates to staff the line

$520

20 hours (language

specialist) X

$26/hour

Interviewing partners

companies to staff the line

for DMI

$338

13 hours (language

specialist) X

$26/hour

Discussions with

[subcontractor] to act as a

sub for DMI

$2,450

7 hours (president) X

$350/hour

Testing the line to route

the calls the proper way

$52

2 hours (language

specialist) X

$26/hour

Recruitment

Staffing

Line Set Up

Total Costs

$4,816

Id. DMI provided no documentation or other evidence to support the hourly rates charged

for each employee, or to prove that the above costs were, in fact, incurred. Transcript at 17273. Instead, DMI admitted that it had just estimated the time and costs incurred in order to

provide costs to the agency. Transcript at 171-75.

CBCA 5517

12

Settlement Discussions and Appeal

ICE responded on August 5, 2016, offering “to offset a portion of the costs [DMI]

incurred preparing for service” in the amount of $31,189.51. Exhibit 51. DMI made a

counteroffer to the agency on August 17, 2016. The counteroffer stated that DMI would be

willing “to accept $54,000 to resolve this matter.” Stipulated Facts ¶ 78. The agency

responded with its final decision on October 5, 2016. The decision stated that the claim was

“denied with the exception of $100.” Exhibit 23. In addition, the decision stated that “the

minimum for this task order is $100 and the maximum ceiling is $379,472.40, which reflects

4,583 hours of translation services.” Exhibit 23. The minimum amount was taken from the

FSS contract. Id. The maximum ceiling was taken from the task order and had been derived

from DMI’s quote for 4583 hours.

DMI timely appealed to the Board on October 17, 2016.

Discussion

Jurisdiction

The Board has jurisdiction to decide this matter pursuant to the Contract Disputes Act

(CDA), 41 U.S.C. §§ 7101-7109 (2012). Resolving the disputes in this appeal does not

require the interpretation of a disputed contract provision in the FSS contract. The ordering

activity (ICE) contracting officer, therefore, had authority to decide the disputed issues in this

case, thereby giving us jurisdiction to entertain this appeal. See 48 CFR 8.406-5(a); Sharp

Electronics Co. v. McHugh, 707 F.3d 1367, 1374 (Fed. Cir. 2013).

The Task Order is a Time and Materials Contract

A threshold issue in this case is the question as to the type of contract used by the

parties. The parties agree that the contract was a task order for commercial services placed

against DMI’s FSS contract. DMI maintains that the task order was an indefinite-delivery,

indefinite-quantity (IDIQ) contract, while ICE contends that it was a time and materials

contract. The answer can be found in the plain language of the task order.

The determination of contract type is governed by an objective reading of the

language of the written agreement, “not by one party’s characterization of the instrument.”

Champion Business Services v. General Services Administration, CBCA 1735, et al., 10-2

BCA ¶ 34,539, at 170,345, modified on reconsideration, 10-2 BCA ¶ 34,598 (citing

Varilease Technology Group, Inc. v. United States, 289 F.3d 795, 799 (Fed. Cir. 2002)); see

LAI Services, Inc. v. Gates, 573 F.3d 1306, 1314 (Fed. Cir. 2009) (citing M.A. Mortenson Co.

v. Brownlee, 363 F.3d 1203, 1206 (Fed. Cir. 2004)). The contract must be read as a whole

CBCA 5517

13

and reasonable meaning must be given to all parts so as not to interpret any provision as

meaningless or so as to create a conflict with other provisions of the contract. Hercules Inc.

v. United States, 292 F.3d 1378, 1380-81 (Fed. Cir. 2002); Jane Mobley Associates, Inc. v.

General Services Administration, CBCA 2878, 16-1 BCA ¶ 36,285, at 176,954. Extrinsic

evidence can serve to confirm that the Board’s interpretation of the plain meaning of the

contract was in fact the parties’ understanding. TEG-Paradigm Environmental, Inc. v.

United States, 465 F.3d 1329, 1338 (Fed. Cir. 2006).

DMI argues that because the task order is for an indefinite number of hours, it must

be an IDIQ contract. In support, DMI cites to Mason v. United States, 222 Ct. Cl. 436

(1980), and FAR part 16 to assert that an indefinite-delivery contract must be one of three

types: “Definite-quantity contracts, requirements contracts, [or] indefinite quantity contracts.”

48 CFR 16.501-2(a); see Mason, 222 Ct. Cl. at 444. Of the three choices, DMI asserts that

the task order is best characterized as an indefinite quantity contract because it is one in

which the Government must order a minimum, but can order up to a maximum, of supplies

or services. To interpret the task order as an IDIQ contract, however, would ignore the parts

of the task order that indicate that it is a time and materials contract, thereby rendering parts

of the contract meaningless.

Here, the plain language of the task order indicated that it is a time and materials task

order placed against an FSS contract. The task order specifically stated that “[t]his is an

incrementally funded, Time & Materials, Task Order against the contractor’s GSA schedule

contract identified above.” The RFQ also indicated that a time and materials contract would

be awarded. The task order incorporated the Time and Materials Payments clause and met

the requirements of FAR 8.404.

FAR 8.404 and FAR part 38 govern task orders placed against FSS contracts. 48 CFR

8.404, 38.301; see Kingdomware Technologies, Inc. v. United States, 136 S. Ct. 1969, 1974

(2016). The only types of order preferences for services listed in FAR 8.404 are firm fixedprice, time and materials, and labor-hour contracts. 48 CFR 8.404(h)(1). FAR part 16, while

it discusses time and materials contracts, is not relevant to FSS contracts. Specifically, FAR

8.404 requires a determination and findings, a ceiling price, and an inability by the agency

to accurately estimate its needs. The agency wrote a determination and findings,

incorporated a ceiling price, and indicated that estimating its needs was problematic. We

find that the parties entered into a time and materials contract.5

5

A question as to whether a time and materials task order was an appropriate

contract vehicle for interpretation services remains.

CBCA 5517

14

There was No Breach Under Either the FSS Contract or the Task Order

DMI asserts that, regardless of whether the task order is a time and materials or IDIQ

contract, ICE breached the contract by preparing a materially misleading estimate and

requiring DMI to rely on the estimate in submitting its bid. The agency counters that, by

definition, a time and materials contract cannot contain a negligent estimate.

The type of contract is relevant to the determination of whether there was a negligent

estimate. A time and materials contract is used when “it is not possible at the time of placing

the order to estimate accurately the extent or duration of the work or to anticipate costs with

any reasonable degree of confidence.” 48 CFR 8.404(h)(3)(i); see also Coastal Government

Services, Inc., ASBCA 49625, 97-1 BCA ¶ 28,888, at 144,049. To use a time and materials

contract, the Government is not required to provide a minimum amount of services requested;

it need only provide a ceiling price. 48 CFR 8.404(h)(3)(ii).

The Board has held that in estimating service hours, the Government does not

guarantee that those hours will be ordered, and the “Government [is] not required under the

contract to order the number of hours listed.” Brink’s/Hermes Joint Venture v. Department

of State, CBCA 1188, 09-2 BCA ¶ 34,209, at 169,115 (finding no negligent estimate when

total services used was only three percent of hours estimated in contract under time and

materials portion). DMI argues that the Government can be held liable for a negligent

estimate, and relies on Womack v. United States, 389 F.2d 793 (Ct. Cl. 1968), for support.

Womack, however, only considered the question of negligent estimate in a requirements

contract. See also Medart, Inc., GSBCA 8939, 91-2 BCA ¶ 23,741, aff’d, 967 F.2d 579

(1992) (applying Womack to a requirements contract). The concept of a negligent estimate

in a time and materials contract is antithetical to the contract vehicle. A time and materials

contract is used, as in this case, where the amount of services needed is unknown and

difficult to predict.

Nonetheless, retracing the mathematical calculations for the agency’s estimated base

hours in the request for quotes shows that the agency made a significant error. The estimated

number of base hours that ICE should have included was approximately ninety-nine, not

4583. Although the agency erroneously estimated the number of base hours expected, the

agency was not required to provide a minimum and cannot be held liable for a negligent

estimate. Thus, there was no breach of contract.

DMI argues that the Board should now read the stated number of base hours (4583)

as a required minimum. However, DMI knew or should have known that the estimate was

the maximum (not minimum) number of hours for CLIN 0001 and was not guaranteed. Not

only was this a time and materials task order, which does not require a minimum, but also

CBCA 5517

15

the ceiling amount identified in the task order for CLIN 0001 was $379,472.40 (equaling

4583 x 60 x $1.38), which was DMI’s quoted price. The agency even reduced the base hour

estimate by 25% and indicated that the hours would be for all languages, not just K’iche’.

There is no evidence that the agency intended the base hours to constitute a minimum, just

the opposite. Moreover, DMI knew that there was no guaranteed minimum. In fact, before

executing a contract with its subcontractor, DMI was told by the agency that it could not

guarantee the number of hours it may order and that it was only providing a maximum

number of hours.

DMI argues that the high number of estimated hours enticed the company into

submitting a quotation, and speculates that it would not have submitted one had it known the

correct estimate. Contract law precludes recovery for speculative damages, however. Story

Parchment Co. v. Paterson Parchment Paper Co., 282 U.S. 555, 562–63 (1931); System

Fuels, Inc. v. United States, 666 F.3d 1306, 1311 (Fed. Cir. 2012). We cannot know and

cannot guess whether DMI would have bid on the contract if the number of estimated base

hours was less, and we, therefore, cannot base our decision on what DMI may have done.

The Government Terminated the Task Order for Its Convenience

DMI contends in the alternative that ICE terminated the contract for its convenience

with the bilateral modification ending the period of performance. ICE argues that DMI

signed the modification, making it a mutual agreement to end the contract that did not invoke

the Termination for Convenience clause.

Parties may change or delete parts of the services required under a contract through

modifications to the contract. John N. Brophy Co., GSBCA 5122, 78-2 BCA ¶ 13,506, at

66,173. Major deletions of contract work, however, may not be accomplished through

modifications. J.W. Bateson Co. v. United States, 308 F.2d 510, 513-14 (5th Cir. 1962);

Praecomm, Inc. v. United States, 78 Fed. Cl. 5, 11 (2007), aff’d, 296 F. App’x 929 (Fed. Cir.

2008). Furthermore, if a contract contains a termination for convenience clause and the

contracting officer could have invoked the clause instead of terminating the contract on some

other, invalid basis, the tribunal will “constructively invoke the clause to retroactively justify

the government’s actions, avoid breach, and limit liability.” Best Foam Fabricators, Inc. v.

United States, 38 Fed. Cl. 627, 638 (1997) (citing John Reiner & Co. v. United States, 325

F.2d 438, 444 (Ct. Cl. 1963)). A directive to end performance of the work will be considered

a termination for the Government’s convenience. Maxima Corp. v. United States, 847 F.2d

1549, 1553 (Fed. Cir. 1988); G.C. Casebolt Co. v. United States, 421 F.2d 710, 712 (Ct. Cl.

1970). Such a clause substitutes termination for convenience recovery costs for any breach

of contract damages that plaintiff might otherwise have had. See Inland Container, Inc. v.

CBCA 5517

16

United States, 512 F.2d 1073, 1081-82 (Ct. Cl. 1975); Drain-A-Way Systems, GSBCA 7022,

84-1 BCA ¶ 16,929, at 84,214-15 (1983).

The bilateral modification to end performance of all work under DMI’s contract was,

in effect, a termination for convenience. The task order explicitly incorporated the GSA

terms and conditions, which included a termination for convenience clause. Because the

modification did more than change part of contract performance, and the contract included

a termination for convenience clause, the modification will be treated as a termination for

convenience by the agency.

The agency’s use of a bilateral modification was, therefore, an invalid method with

which to end the contract. The cases cited by the agency to support the argument that the

Board should not disturb a “voluntary, bilateral contract action in favor of a constructive

termination,” Olbeter Enterprises, Inc. v. United States Postal Service, PSBCA 6543, 16-1

BCA ¶ 36,281, at 176,943, concerned only partial changes to contract work and are

distinguishable from the current facts. See Justman Freight Lines, Inc. v. United States

Postal Service, PSBCA 6428, 15-1 BCA ¶ 35,819, at 175,163 (2014) (refusing to disturb

mutually agreed upon change deleting only a portion of contract work); Honeycomb Co. of

America, ASBCA 44612, 02-1 BCA ¶ 31,703, at 156,588 (2001) (considering partial

reduction in work not a termination because was voluntary bilateral modification designating

the reduction as a change); Seaboard Surety Co., ASBCA 6716, 1962 BCA ¶ 3407, at 17,488

(applying changes clause when parties agreed to elimination of some contract work and

downward adjustment of contract price). Olbeter, cited by ICE to support its argument that

a voluntary agreement should not be disturbed, does not concern a partial change, though it

too does not apply here. Olbeter held that the agency could not invoke a retroactive

termination to limit the Government’s damages because the contract remained in force until

the Government terminated the contract under the termination clause in the contract. 16-1

BCA at 176,943. Here, the agency never invoked the termination clause, but, nevertheless,

attempted to end the contract. The agency could not terminate the entire contract without

using the termination clause.

ICE argues that the Government cannot be found liable for declining to issue a

termination for convenience because it is never obligated to terminate a contract for

convenience. Simply because the Government is not obligated to do so does not mean that

its actions cannot constitute a termination for convenience, as they did here.

The agency also argues that DMI waived its right to termination costs by signing the

bilateral modification. The modification, however, did not contain no-cost termination or

release language. See 48 CFR 43.204(c), 49.603-6. The modification made no mention of

CBCA 5517

17

how DMI’s incurred costs would be treated. The determination of damages, therefore, is

determined by the Termination for Convenience clause in the task order.

Termination for Convenience Remedy

Compensation under the termination for convenience clause in the task order is not

limited to a percentage of work performed prior to termination plus settlement charges, but

may include other expenses based on a consideration of “reasonable charges” a contractor

incurred. ACM Construction & Marine Group, Inc. v. Department of Transportation, CBCA

2245, et al., 14-1 BCA ¶ 35,537, at 174,155 (citing Russell Sand & Gravel Co. v.

International Boundary and Water Commission, CBCA 2235, 13 BCA ¶ 35,455, at 173,869);

Corners & Edges, Inc. v. Department of Health and Human Services, CBCA 693, et al., 08-2

BCA ¶ 33,961, at 168,022-23. One of our predecessor boards observed that “[i]t is axiomatic

that . . . one must strike a balance between the need for technical compliance with regulatory

requirements and the need for basic fairness.” Spectrum Leasing Corp. v. General Services

Administration, GSBCA 12189, 95-1 BCA ¶ 27,317, at 136,185-86 (1994).

The basic principles governing a termination for convenience settlement are stated in

the FAR and provide that:

A settlement should compensate the contractor fairly for the work done and the

preparations made for the terminated portions of the contract. . . . Fair

compensation is a matter of judgment and cannot be measured exactly. . . .

The use of business judgment, as distinguished from strict accounting

principles, is the heart of a settlement.

48 CFR 49.201(a).

During the task order period of performance, DMI provided no interpretation services.

However, DMI did incur costs in preparing to perform the task order, primarily the cost of

providing a live line to K’iche’ interpreters twenty-four hours a day and seven days a week.

This cost was incurred from August 10, 2015, the day DMI’s line went live, to

September 3, 2015, the day DMI instructed its subcontractor to pause.

The costs to which DMI is entitled are the reasonable costs paid to its subcontractor

for the time period of August 10 to September 3, 2015. The standards for determining the

allowability of a contractor’s costs when settling a subcontractor’s claims are the

“reasonableness and prudence of the settlement, including the competence and good faith

with which the negotiations were conducted and the adequacy of the information upon which

the settlement was based.” General Dynamics Land Systems, Inc., ASBCA 52283, 02-1

CBCA 5517

18

BCA ¶ 31,659, at 156,411 (2001) (citing Boston Towing & Salvage Co., ASBCA 41357,

92-2 BCA ¶ 24,864, at 124,031).

DMI’s subcontract, while reasonable, did not accurately reflect the hours of work

expected. DMI guaranteed its subcontractor a fixed monthly payment based on the agency’s

4583 estimated hours. Despite the fact that the agency’s estimate turned out to be wrong, at

the time it executed the subcontract, DMI knew that 4583 was the maximum (not minimum)

number of hours for interpretation services estimated by the agency. DMI also knew that the

agency did not guarantee that it would order 4583 or any other number of hours. In fact, the

agency specifically told DMI to expect only 75% of the maximum estimated 4583 hours if

only providing interpretation services, which DMI was. DMI also expected the hours to be

divided among the different languages that ICE needed interpreted, yet DMI was only

interpreting K’iche’. In addition, while the agency preferred “24/7 coverage,” such coverage

was not required, and DMI had not promised to provide “24/7 coverage” in its bid proposal.

Nonetheless, because it was so difficult to find K’iche’ interpreters, DMI accepted the

subcontractor’s terms (guaranteed payment for 22,500 minutes per month at $1.25 per

minute) in order to provide the services required. DMI believed that 4583 was a target and

that the agency would come close to its estimate based on DMI’s previous contract

experience. Even so, DMI provided for a ninety-day trial period for the subcontract, after

which time it would assess the actual agency demand. DMI, however, did not have the

opportunity to reassess its subcontract based on demand due to the agency’s termination.

In determining DMI’s termination for convenience costs, we must take into

consideration that ICE’s estimate was erroneous, that ICE failed to pass on DMI’s number

to its field offices, and that ICE failed to tell DMI that its interpretation line had not been

made available to anyone. The erroneous estimate led DMI to enter into a subcontract that,

in hindsight, was unnecessarily costly. The agency’s failure to pass on DMI’s number to the

field offices not only operated to DMI’s detriment, but also was a failure by ICE to mitigate

DMI’s costs. Effectively, the agency let DMI incur costs that it had no chance to recoup

either at the time, or during the remainder of the contract. The agency also allowed DMI to

make decisions about DMI’s performance and termination without significant information

as to why it had received no calls on its interpretation line. As such, DMI remained in the

preparation stage until it was terminated. Fairness dictates that DMI recover some of those

costs.

DMI paid its subcontractor for August 10 to September 16, 2015, in the amount of

$35,897.50. DMI did, however, mitigate the agency’s costs by pausing its subcontract from

September 3 to 16, 2015. During this time, the interpretation line was not active. We do not

CBCA 5517

19

find that simply because DMI chose to pay its subcontractor for services while the line was

not active, DMI is entitled to these costs.

DMI paid its subcontractor the prorated share of 22,500 minutes per month, which

came out to $19,960 for August and $15,937.50 for September. However, these costs should

be reduced to reflect the fact that DMI could only have reasonably expected 75% of the 4583

hours, or 3437 hours, as the maximum number of hours for interpretation services. That

number should have been even less because DMI was only providing interpretation of one

language. DMI, however, could not know that 4583 or even 3437 hours was far beyond the

number of hours of services actually possible. Thus, for the month of August, 22,500

minutes-per-month equals 725.80 minutes per day. For the twenty-two days in August

during which the line was live, DMI would owe the subcontractor for 15,967.60 minutes.

Based on the $1.25 rate per minute DMI was charged, we find that, for August, DMI would

be entitled to $19,959.50 of its subcontractor costs. Taking the reasonably expected 75% of

those hours equals $14,969.63.

For September, 22,500 minutes per month equals 750 minutes per day. For the three

days in September during which the line was live, DMI would owe the subcontractor for

2250 minutes. Based on the $1.25 rate, we find that, for September, DMI would be entitled

to $2812.50 of its subcontractor costs. Again taking 75% of those hours, DMI is entitled to

$2109.38. Taking the total for August and September, DMI is therefore entitled to a total

recovery of its preparation costs of $17,079.

DMI has also asked for G&A costs and profit. DMI is not entitled to any of these

costs. Under the FAR payments clause for time and materials contracts, the hourly rates must

“include wages, indirect costs, [G&A] expense, and profit.” 48 CFR 52.232-7(a)(4). As

such, these costs are already built into the contract prices and cannot be claimed by the

contractor in addition to its recovery for hours performed. Since DMI did not perform any

interpretation services, however, there is no recovery for G&A or profit. Additionally,

anticipatory profits and consequential damages are not recoverable. See International Data

Products Corp. v. United States, 492 F.3d 1317, 1323-24 (Fed. Cir. 2007); Shin Enterprises,

Inc., ASBCA 16542, 72-1 BCA ¶ 9391, at 43, 614 (determining that if the contractor has

incurred no costs, no profit recovery is allowed); see also 48 CFR 49.202(a). DMI’s claim

for G&A expenses and profit is, therefore, denied.

DMI also seeks compensation for costs incurred in seeking a resolution of the issues

in the amount of $17,316.91. DMI has suggested that these costs included attorney fees,

accountant fees, and consultant fees. While settlement expenses, including accounting, legal,

clerical, and similar costs reasonably necessary for the preparation and presentation of

settlement claims to the contracting officer are generally allowable, 48 CFR 31.205-42(g),

CBCA 5517

20

the contractor has the burden of proving these costs were incurred “with sufficient certainty

so that the determination of the amount . . . will be more than mere speculation.” Nu-Way

Concrete Co. v. Department of Homeland Security, CBCA 1411, 11-1 BCA ¶ 34,636, at

170,698 (2010) (quoting Benmol Corp. v. Department of the Treasury, GSBCA 16374-TD,

05-1 BCA ¶ 32,897, at 162,979); see also Lisbon Contractors, Inc. v. United States, 828 F.2d

759, 767 (Fed. Cir. 1987). DMI failed to substantiate its costs. DMI did not provide legal

bills, consultant or accountant invoices, or any other substantiating documentation. In fact,

DMI’s president testified that he did not believe that accounting or consultant costs were

even incurred. Award of these costs would be mere speculation. For these reasons, this

portion of DMI’s claim is denied.

DMI has failed to meet its burden of proving that it is entitled to the $4816 in costs

it claims for setting up the line. DMI only estimated the time expended after-the-fact and

failed to maintain a log or keep track of the time claimed. DMI also failed to provide any

payroll records, canceled checks, or project documentation to support these costs or hourly

rates. Moreover, the hours claimed and hourly rates are not supported by the record. Fiftysix hours spent on research seems unreasonably high given that DMI had a prior relationship

with the subcontractor and had already identified the subcontractor prior to its bid.

Therefore, the costs DMI claimed for researching sources to staff the line are not allowable.

The seven hours spent by DMI’s CEO in discussions with the subcontractor prior to

execution of the subcontract also seem to be unreasonably high and are not allowed. The

hourly rate charged lacks support. The other charges claimed by DMI are similarly

unsupported by the record and are therefore not allowed.6

Decision

The appeal is GRANTED IN PART in the amount of $17,079. The balance of

the costs claimed is denied.

_____________________________

ERICA S. BEARDSLEY

Board Judge

6

ICE argues that the $100 minimum in the FSS contract applies to the task

order. As a result of the damages awarded for the termination for convenience, the

application of the $100 minimum to the task order need not be decided.