West 125th Dev. LLC v. Song

West 125th Dev. LLC v Song

2024 NY Slip Op 33934(U)

November 4, 2024

Supreme Court, New York County

Docket Number: Index No. 651051/2023

Judge: Louis L. Nock

Cases posted with a "30000" identifier, i.e., 2013 NY Slip

Op 30001(U), are republished from various New York

State and local government sources, including the New

York State Unified Court System's eCourts Service.

This opinion is uncorrected and not selected for official

publication.

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

SUPREME COURT OF THE STATE OF NEW YORK

NEW YORK COUNTY

PRESENT: HON. LOUIS L. NOCK PART 38M

Justice

---------------------------------------------------------------------------------X INDEX NO. 651051/2023

WEST 125TH DEVELOPMENT LLC,

MOTION DATE 02/27/2023

Petitioner,

MOTION SEQ. NO. 001

-v-

JEEMI SONG, ECDO HOUSES ASSOCIATES LIMITED

PARTNERSHIP, 42 WEST 126 STREET REALTY CORP, W

126 GROUP LLC, 36 WEST 126TH STREET REALTY LLC, DECISION, ORDER +

BVK 55 WEST 125TH STREET, LLC, and DUL DUL JUDGMENT ON MOTION

REALTY LLC A/K/A DUL DUL REALTY, LLC,

Respondents.

---------------------------------------------------------------------------------X

The following e-filed documents, listed by NYSCEF document numbers (Motion 001) 2, 19, 20, 21, 22,

23, 24, 25, 26, 27, 28, 29, 30, 31, 32, 33, 34, 35, 36, 37, 38, 39, 40, 41, 42, 43, 44, 45, 46, 47, 48, 49, 50,

52, 53, 54, 55, 56, 57, 58, 59, 60, 61, 62, 63, 64, 72, 73, 74, 76, 77, 78, 79, 80, 81, 82, and 85

were read on this R.P.A.P.L. SPECIAL PROCEEDING .

LOUIS L. NOCK, J.S.C.

Upon the foregoing documents, the petition of West 125th Development LLC

(“petitioner”) for a license to enter adjoining property pursuant to RPAPL 881 is granted, for the

reasons set forth in the petition and supplemental submissions (NYSCEF Doc. Nos. 1, 3-4, 52-

54, 78-79) and the exhibits attached thereto, in which the court concurs, as summarized herein.

The following is, unless otherwise stated, undisputed. Petitioner is the owner and

developer of the premises located at 35 West 125th Street, New York, New York, and 33 West

125th Street, New York, New York (the “property”), upon which it wishes to build a 21-story

mixed-use commercial building. Respondents are owners of the surrounding premises.

Specifically, respondent Jeemi Song owns the property located at 46 West 126th Street;

respondent ECDO Houses Associates Limited Partnership (“ECDO”) owns the property located

at 44 West 126th Street; respondent 42 West 126th Realty Corp. (“42 West”) owns the property

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 1 of 10

Motion No. 001

1 of 10

[* 1]

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

located at that address; respondent W 126 Group LLC (“W 126”) owns the property located at 40

West 126th Street; respondent 36 West 126th Street Realty LLC (“36 West”) owns the property

located at that address; respondent BVK 55 West 125th Street, LLC (“BVK”) owns the property

located at that address; and respondent Dul Dul Realty, LLC (“Dul Dul”), owns the properties

located at 31 West 125th Street (the “125th Street property”) and 34 West 126th Street (the

“126th Street property”) (verified petition, NYSCEF Doc. No. 1, ¶¶ 4-11). Petitioner’s property

abuts the properties owned by respondents, as well as the property located at 50 West 126th

Street, whose owner is not a party to this proceeding (id., ¶ 12). Plaintiff has discontinued this

proceeding against respondents Song and BVK (NYSCEF Doc. Nos. 83, 84), and has an

agreement with the owner of 50 West 126th Street (Cusack reply affirmation, NYSCEF Doc. No.

52, ¶ 20). Respondents ECDO, 42 West, W 126, and 36 West have defaulted in answering the

petition. Accordingly, the remaining dispute is between petitioner and Dul Dul. The parties

have been negotiating the terms of a license since prior to the commencement of this special

proceeding, and each side accuses the other of not negotiating in good faith.

At the outset, petitioner asserted that it needed access to respondents’ properties in order

to install “overhead protections, roof protections, and a construction fence,” as well as to perform

a preconstruction survey (verified petition, NYSCEF Doc. No. 1, ¶ 14; Menzak aff., NYSCEF

Doc. No. 4, ¶¶ 13-17). Such protections are necessary under the New York City Building Code.

Petitioner sought a license to install such protections to last 36 months, the expected length of the

construction (verified petition, NYSCEF Doc. No. 1 at 6). According to Dul Dul’s architect,

Carl Bradley Cronk, however, additional plans for support of excavation work, tiebacks on the

party wall between the properties, and significant underpinning of Dul Dul’s properties were not

submitted with the petition in this proceeding (Cronk aff., NYSCEF Doc. No. 45, ¶¶ 14-15). It is

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 2 of 10

Motion No. 001

2 of 10

[* 2]

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

further asserted that the plans submitted with the petition in this proceeding were incomplete,

and lacking certain protections required by the Building Code (id., ¶¶ 21-31).

In reply, petitioner asserts that, to the extent its plans are incomplete or not approved by

the New York City Department of Buildings (“DOB”), Dul Dul’s unwillingness to allow access

for a preconstruction survey is a significant cause of the delay (Menzak reply aff., NYSCEF Doc.

No. 53, ¶¶ 21-28). Underpinning, a substantial permanent encroachment on respondent’s

property, cannot be granted on this application, which petitioner acknowledges, and, indeed,

petitioner’s architect, Yuriy Menzak, states that petitioner did not include an underpinning

request in its petition for that reason (id., ¶¶ 29-30). Petitioner also proposes that underpinning

may not be necessary, and that tiebacks are minimally intrusive and necessary to secure the party

wall (id., ¶¶ 31-37).

Prior to oral argument on this matter in May of this year, petitioner submitted a

supplemental affidavit of its site safety contractor, in which Aaron Broyn, the contractor’s

president, avers that petitioner has reconfigured its design and construction plans so as to

drastically reduce the amount of potential intrusion onto respondent’s properties (Broyn aff.,

NYSCEF Doc. No. 79, ¶ 4). Specifically, petitioner now requests a 2-3 hour period to access the

roof of the 125th Street property to install and then later dismantle an “engineered enclosure

system” to provide protection for respondents’ properties (id., ¶¶ 9-10). The roof of the 125th

Street property will be protected by cantilevered netting suspended from petitioner’s property

(id.). This design change will forgo the need to install further window protections on the 125th

Street property (id., ¶¶ 11). The revised plans have been approved by the DOB (id., ¶ 5; revised

plans, NYSCEF Doc. No. 80).

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 3 of 10

Motion No. 001

3 of 10

[* 3]

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

As of now, the requested access to Dul Dul’s properties is as follows: a pre-construction

survey, temporary roof access to install and dismantle the engineered enclosure system,

installation and monitoring of vibration and crack monitors, installation of weatherproofing on

the exposed foundation and party walls, relocation of the 125th Street property’s chimney,

construction of a five foot scaffold in the rear yard of the 126th Street property, and any access

necessary to maintain the protective netting suspended from the project above the 125th Street

property once the project reaches the ninth floor (id., ¶¶ 15-17). Petitioner’s planned actions are

required by the Building Code to protect respondents’ properties (id., ¶ 18; NY City Bldg Code

[Administrative Code of City of NY, title 28, ch 7] §§ BC 3309.1, et seq.). As set forth above,

only Dul Dul remains in opposition to the petition.

A petition for access is governed by RPAPL 881, which provides as follows:

When an owner or lessee seeks to make improvements or repairs to real property

so situated that such improvements or repairs cannot be made by the owner or

lessee without entering the premises of an adjoining owner or his lessee, and

permission so to enter has been refused, the owner or lessee seeking to make such

improvements or repairs may commence a special proceeding for a license so to

enter pursuant to article four of the civil practice law and rules. The petition and

affidavits, if any, shall state the facts making such entry necessary and the date or

dates on which entry is sought. Such license shall be granted by the court in an

appropriate case upon such terms as justice requires. The licensee shall be liable

to the adjoining owner or his lessee for actual damages occurring as a result of the

entry.

“A proceeding pursuant to RPAPL 881 is addressed to the sound discretion of the court, which

must apply a reasonableness standard in balancing the potential hardship to the applicant if the

petition is not granted against the inconvenience to the adjoining owner if it is granted” (Queens

Theater Owner, LLC v WR Universal, LLC, 192 AD3d 690, 690 [2d Dept 2021]). The court may

consider “the nature and extent of the requested access, the duration of the access, the needed

protections for the adjoining property, the lack of an alternative means to perform the work, the

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 4 of 10

Motion No. 001

4 of 10

[* 4]

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

public interest in the completion of the project, and the measures in place to ensure the financial

compensation of the adjoining owner for any damage or inconvenience resulting from the

intrusion” (id. at 690-91). “[B]ecause the respondent to an 881 petition has not sought out the

intrusion and does not derive any benefit from it[, e]quity requires that the owner compelled to

grant access should not have to bear any costs resulting from the access” (Matter of Van Dorn

Holdings, LLC v 152 W. 58th Owners Corp., 149 AD3d 518, 518-19 [1st Dept 2017]).

“Damages and attorneys’ fees are, therefore, appropriately considered in the context of an

RPAPL 881 proceeding” (269-273 14th St N.Y. Corp. v Stein, 221 AD3d 807, 809 [2d Dept

2023]).

Here, as to Dul Dul, petitioner contacted Dul Dul’s counsel in November 2022, at which

time counsel refused to even discuss the matter further until petitioner had paid counsel $8,100

for his services related to the potential license agreement and escrowed a further $20,000 deposit

(Cusack reply aff., NYSCEF Doc. No. 52, ¶¶ 6-8). Subsequently, Dul Dul’s counsel continued

to demand payment of attorneys’ fees before discussing a license agreement (id., ¶¶ 8-9). Thus,

petitioner has sufficiently sought a license that Dul Dul has refused, contrary to Dul Dul’s

position. Further, the inconvenience to respondents is mild, given the scope of the potential

protections. Without the grant of a license, petitioner will not be able to construct its building,

and petitioner has proposed to take several steps to protect respondents’ properties (Matter of

New York Pub. Lib. v Condominium Bd. of the Fifth Ave. Tower, 170 AD3d 544, 545 [1st Dept

2019]). The terms proposed by petitioner include the detailed protective measures described

above, and petitioner has agreed to maintain an insurance policy covering respondents and their

properties, to indemnify and hold harmless respondents from any liability or damages caused by

the construction, and address any violations or mechanic’s liens assessed against respondents’

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 5 of 10

Motion No. 001

5 of 10

[* 5]

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

properties (proposed order, NYSCEF Doc. No. 62). Moreover, the protective measures

petitioner will install are required by the Building Code (Matter of Queens Coll. Special Projects

Fund, Inc. v Newman, 154 AD3d 943, 944 [2d Dept 2017]). Under such circumstances, the grant

of a license is proper (e.g. Mindel v Phoenix Owners Corp., 210 AD2d 167, 167 [1st Dept 1994]

[“We adopt a standard of reasonableness in concluding that defendant is prepared to do all that is

feasible to avoid injuries resulting from its entry upon plaintiffs' properties, and that an RPAPL

881 license was therefore properly granted”]).

Dul Dul’s arguments in opposition are unavailing. Tiebacks, the only permanent

encroachment contemplated by petitioner, are a relatively insubstantial protective measure to

ensure the stability of the party wall and a proper subject of a license (Tompkins 183 LLC v

Frankel, 2019 WL 6654136 at *4 [Sup Ct NY County 2019] [“Although Respondent strongly

objects to the party wall tie-backs, such protection is, in this Court's opinion, the most reasonable

option for the parties under the circumstances and is virtually unavoidable”] [internal quotation

marks and citation omitted]). The underpinning objected to by Dul Dul has been removed from

petitioner’s project plans, and the revised plans presented to the court have been approved by the

DOB.

Nor are all the terms proposed by respondent reasonable. Insurance coverage and

indemnity are sufficient financial protection for respondents (Matter of Queens Coll. Special

Projects Fund, Inc., 154 AD3d at 944 [“the appellant would be financially protected by the

naming of the appellant as an additional insured on the relevant construction insurance policies

and by the petitioner's promise to indemnify her for any loss”]). Dul Dul offers only speculation

that an additional bond or escrow agreement would also be required. Dul Dul’s suggestion that

the term of the license should be six months, renewable for three month increments thereafter is

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 6 of 10

Motion No. 001

6 of 10

[* 6]

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

also not necessary. Petitioner seeks a license for 36 months, and the courts have held that similar

lengths of time are reasonable (id. at 944 [18-24 months; see also DDG Warren LLC v Assouline

Ritz 1, LLC, 138 AD3d 539, 540 [1st Dept 2016] [30 months]). Dul Dul does not establish that a

shorter term of the license is necessary. Certain other terms regarding notice of damages,

petitioner’s responsibilities related to mechanic’s liens and DOB violations, and petitioner’s

prompt repair of damage to respondents’ properties, have been incorporated into petitioner’s

proposed license terms. The court will adopt Dul Dul’s request that respondents be allowed to

repair damage to their own properties at petitioner’s expense, provided that petitioner is afforded

a reasonable period of time to conduct repairs first.

There remains the issue of financial compensation, in the form of a monthly license fee

and compensation for Dul Dul’s expenses. As to the license fee, as cited by Dul Dul, courts have

frequently assessed a $2,000-$3,500/per month license fee for protections similar to those

presently being proposed by petitioner for the length of time proposed by petitioner (e.g.

Tompkins, supra; 115 St Developers LLC I. 1629 Realty Inc., 2017 WL 2909356 [Sup Ct NY

County 2017]; Columbia Grammar & Preparatory Sch. v. IO W 93rd St. Hous. Dev. Fund Corp.,

2015 NY Slip Op 31519[U] [Sup Ct NY County 2015]). Thus, neither petitioner’s suggestion of

$1,500/month nor Dul Dul’s initial demand of $22,500/month are reasonable. Based on the fees

awarded by other courts addressing the matter, the court finds a $2,500/month license fee to each

respondent to be sufficient.

As to Dul Dul’s expenses relating to the application: Dul Dul, pursuant to two

supplemental affirmations submitted by counsel, seeks $70,127.25 in legal fees charged by

counsel, and $16,400 in expert fees charged by Dul Dul’s architect Cronk. Petitioner offers no

meaningful objection to the fees incurred by Cronk. As to the attorneys’ fees, however,

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 7 of 10

Motion No. 001

7 of 10

[* 7]

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

petitioner states that it has already paid Dul Dul $18,100 in counsel fees. Petitioner challenges

the reasonableness of Dul Dul accruing almost $40,000 of attorneys’ fees in April and May 2023

alone, and asserts that none of the additional attorneys’ fees were generated in an effort to

progress the case. Petitioner asks the court to deny any further award of attorneys’ fees.

“The determination of a reasonable attorney's fee is left to the sound discretion of the trial

court” (RMP Capital Corp. v Victory Jet, LLC, 139 AD3d 836, 839-40 [2d Dept 2016]). It is the

claimant’s burden to demonstrate that the fees sought are reasonable (Matter of Karp, 145 AD2d

208, 216 [1st Dept 1989]). Upon review of the invoices, the court finds that Dul Dul is not

entitled to recoup the entirety of its exorbitant fee demand. The invoices provided by counsel do

not provide a “detailed breakdown . . . of the time and labor expended” (id.), but instead engage

in “block-billing” by grouping different tasks together by attorney in single entries, showing

several different tasks without regard for the amount of time spent on each task. Moreover, Dul

Dul fails to provide sufficient information regarding “the difficulty of the matter, the skill, time

and labor required, [counsel’s] experience, ability and reputation, and the customary fee for

similar services” (Matter of Jeffrey, 214 AD2d 353, 353 [1st Dept 1995]). A 25% reduction for

the use of block-billing has been found a provident exercise of discretion (RMP Capital Corp.,

139 AD3d at 840). Further, in one of the cases cited by Dul Dul, the court awarded

approximately one-third of the fees sought due to counsel’s failure to provide sufficient

information justifying the fee and use of block-billing (Tompkins, supra, at *5). In light of the

nature of this case, the different sets of plans and course of negotiations requiring counsel’s time

and labor, the amount of fees already paid to Dul Dul, and the deficiencies noted above, the court

finds that an award of $35,063.63, or approximately half of what Dul Dul seeks, is sufficient

compensation.

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 8 of 10

Motion No. 001

8 of 10

[* 8]

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

Accordingly, it is hereby

ADJUDGED that the petition is granted, and petitioner is awarded a license to enter the

adjoining properties of respondents ECDO Houses Associates Limited Partnership; 42 West

126th Realty Corp.; W 126 Group LLC; 36 West 126th Street Realty LLC; and Dul Dul Realty,

LLC, to perform the work set forth in the supplemental affirmation of Aaron Broyn (NYSCEF

Doc. No. 79) and the revised plans (NYSCEF Doc. No. 80) upon the following terms and

conditions:

1. The license shall be for a period of 36 months, or whenever the exterior of

petitioner’s new building is complete, whichever is sooner;

2. Petitioner’s workmen and contractors shall have access to respondents’ properties

only from Mondays through Fridays, between the hours of 8:30 am and 5:00 pm;

3. Petitioner’s work on respondents’ properties shall conform to petitioner’s site safety

plan, the Building Code of the City of New York, and all other applicable rules and

regulations of the City of New York;

4. Petitioner shall maintain primary and non-contributory commercial general liability

insurance, in the amount of $2,000,000 per occurrence and $4,000,000 general

aggregate, covering respondents by name, and listing respondents’ properties as part

of the covered work-site, for any loss respondents may incur for property damage,

personal injury, or wrongful death, including any liability under the New York State

Labor Law, as a result of petitioners’ work for the entire duration of this license;

5. Petitioner shall indemnify and hold respondents harmless for any liability, claims,

damages or losses, including attorneys’ fees respondents may incur as a result of

petitioner’s work, whether or not caused by the negligence of petitioner or its

employees, agents, contractors or subcontractors;

6. Petitioner shall immediately report, in writing, to respondent any damage to

respondents’ premises caused by petitioner’s work. If, following a reasonable period

of time, petitioner fails to remediate the damage, the affected respondent may repair

the damage at petitioner’s expense;

7. Petitioner shall cure any violation placed against respondents’ properties by any

governmental or administrative agency as a result of petitioner’s work. Petitioner

shall reimburse respondents for any fines or penalties imposed as a result of such

violations;

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 9 of 10

Motion No. 001

9 of 10

[* 9]

INDEX NO. 651051/2023

NYSCEF DOC. NO. 86 RECEIVED NYSCEF: 11/04/2024

8. Petitioners shall take all steps necessary to remove any mechanic’s lien, or other

encumbrance against respondents’ properties arising from petitioner’s work;

9. Petitioners shall pay respondents each a license fee of $2,500 per month;

10. The term of this license shall commence the day after Petitioner has provided to

Respondent a copy of the insurance policy and the license fee; and

11. If petitioner has reason to believe that the term of the license need be extended

beyond the original term, petitioner shall, within 30 days of determining that an

extension is necessary, so notify respondents and the court, and upon such

notification, the court shall hold a hearing as to the necessity of the continuance of the

license.

AND IT IS FURTHER ORDERED that this court retains jurisdiction over this matter to

resolve any disputes over the interpretation, implementation, or enforcement of this license.

This constitutes the decision, order, and judgment of the court.

ENTER:

11/4/2024 $SIG$

DATE LOUIS L. NOCK, J.S.C.

CHECK ONE: CASE DISPOSED X NON-FINAL DISPOSITION

APPLICATION:

X GRANTED

SETTLE ORDER

DENIED GRANTED IN PART

SUBMIT ORDER

□ OTHER

□

CHECK IF APPROPRIATE: INCLUDES TRANSFER/REASSIGN FIDUCIARY APPOINTMENT REFERENCE

651051/2023 WEST 125TH DEVELOPMENT LLC vs. SONG, JEEMI ET AL Page 10 of 10

Motion No. 001

10 of 10

[* 10]